K3 Barn Repairs, Prairie du Sac, Wisconsin

United States Department of Agriculture Agricultural Research Service 100% Design Documents Contract No. 12505B23D0008/12505B24F0196 Order Date. 9/13/24 BED Project No. 024130 K3 Barn Repairs U.S. Dairy Forage Research Center (DFRC) USDA – ARS S8822 Sunset Drive Prairie du Sac, WI 53578 Date: July 29, 2026 Bailey Edward Design, Inc. 35 E Wacker Drive Suite 2800 Chicago, IL 60601 312-440-2300 -- 1 of 125 -- K3 Barn Repairs USDA-ARS Prairie du Sac, WI TOC-1 TABLE OF CONTENTS DIVISION 01 GENERAL REQUIREMENTS SECTION 01 10 00 SUMMARY SECTION01 14 00 WORK RESTRICTIONS SECTION 01 29 00 PAYMENT PROCEDURES SECTION 01 31 00 PROJECT MANAGEMENT AND COORDINATION SECTION 01 31 20 CRITICAL PATH METHOD SCHEDULING SECTION 01 32 00 CONSTRUCTION PROGRESS DOCUMENTATION SECTION 01 32 33 PHOTOGRAPHIC DOCUMENTATION SECTION 01 33 00 SUBMITTAL PROCEDURES SECTION 01 35 16 ALTERATION PROJECT PROCEDURES SECTION 01 40 00 QUALITY REQUIREMENTS SECTION 01 42 00 GENERAL REFERENCES SECTION 01 50 00 TEMPORARY FACILITIES AND CONTROLS SECTION 01 59 50 SAFETY & HEALTH SECTION 01 60 00 PRODUCT REQUIREMENTS SECTION 01 70 00 EXECUTION REQUIREMENTS SECTION 01 73 10 CUTTING AND PATCHING SECTION 01 74 19 CONSTRUCTION NON-HAZARDOS WASTE MANAGEMENT AND DISPOSAL ALL DELIVERY METHODS SECTION 01 77 00 CLOSEOUT PROCEDURES SECTION 01 78 10 PROJECT RECORD DOCUMENTS SECTION 01 78 22 OPERATION AND MAINTENANCE DOCUMENTATION SECTION 01 79 00 DEMONSTRATION AND TRAINING DIVISION 05 METALS SECTION 05 10 00 STRUCTURAL METAL FRAMING SECTION 05 50 00 METAL FABRICATIONS DIVISION 06 WOOD AND PLASTICS SECTION 06 10 00 ROUGH CARPENTRY END OF TABLE OF CONTENTS -- 2 of 125 -- K3 Barn Repairs USDA-ARS Prairie du Sac, WI SUMMARY 01 10 00 - 1 SECTION 01 10 00 – SUMMARY PART 1 GENERAL 1.1 PROJECT INFORMATION A. Project Name and Location: 1. USDA ARS DFRC K3 Barn Repairs 2. U.S. Dairy Forage Research Center (DFRC) USDA_ARS S8822 Sunset Drive Prairie du Sac, WI 53578 B. Project Summary Description. The Work of this Contract is defined by the Contract Documents and generally consists of, but is not limited to, the following: 1. The documents define general work necessary to accommodate upgrades to the steam condensate return system and the electrical distribution system. Coordinate schedule, routing, shutdowns, temporary power, deliveries, trash enclosure location, and all other logistics necessary to complete upgrades amongst the trades, with the existing conditions and with the COR. 2. Animal bumping and machine collisions have caused damage to structural support columns. Repair damaged structural support columns per the Bid Documents. Add additional tube steel support columns at the overhand to limit the deflection in the support beam. 3. Provide operations and maintenance manuals, record documents, testing, warranty and all closeout documentation. 4. Reference also the Project Description, Sheet G000 for additional information. C. Architect/Engineer: The term Architect/Engineer refers to the project designer. The Architect/Engineer's status relative to the construction will be stated in writing by the Contracting Officer prior to the pre-construction conference. The project was managed by: Bailey Edward Design, Inc. 1103 S. Mattis Avenue Champaign, IL 61821 Attn: Kevin Schnebly (217) 363-3375 kschnebly@baileyedward.com D. Project Delivery Method: Traditional Bid-build E. The Contracting Officer for the project is: Mithilesh Patel USDA, ARS 5601 Sunnyside Avenue Beltsville, MD 20705 (301) 837-8755 Mithilesh.Patel@usda.gov -- 3 of 125 -- K3 Barn Repairs USDA-ARS Prairie du Sac, WI SUMMARY 01 10 00 - 2 F. Primary Contact – Contracting Officer’s Rep: TBD USDA, ARS 1815 North University Street Peoria, IL 61604 (309) 236-1038 (office) _________@usda.gov 1.2 MISCELLANEOUS PROVISIONS A. Work in existing facilities shall correspond in all respects with the existing conditions to which it connects, or to similar existing conditions, in materials, workmanship and finish unless noted otherwise. B. Alterations to Existing Conditions: Existing conditions shall be cut, drilled, removed, temporarily removed, or removed and replaced, as necessary for performance of Work under the Contract and in conformance with Health and Safety requirements outlined in section 01 59 50 - Safety and Health. Work out of alignment where exposed by removal of existing work shall be called to the attention of USDA. Necessary corrective work shall be as directed. 1. Replacements of existing conditions that are removed shall match similar existing conditions. 2. Unless otherwise indicated, existing structural members shall not be cut or altered without authorization by the Contracting Officer. 3. Adjacent work remaining in place, which are damaged or defaced during the Work, shall be restored to the condition existing at time of award of Contract to the satisfaction of the Government. C. Existing structures will remain in place. D. Removed items indicated to remain the property of the Government shall be stored in the building where directed by the Contracting Officer E. Existing utility services with related meters and equipment will remain in place. PART 2 PRODUCTS (Not Applicable) PART 3 EXECUTION (Not Applicable) END OF SECTION 01 10 00 -- 4 of 125 -- K3 Barn Repairs USDA-ARS Prairie du Sac, WI WORK RESTRICTIONS 01 14 00 - 1 SECTION 01 14 00 - WORK RESTRICTIONS PART 1 - GENERAL 1.1 CONTRACTOR USE OF PREMISES A. The Contractor will review and document the existing conditions surrounding the project premises. Provide documentation to USDA-ARS prior to the commencement of any construction activity. B. The Contractor shall limit use of the premises to the work in areas indicated, and to allow for Government occupancy and public use. 1. Confine operations at the site to areas indicated in plans. Do not disturb portions of the site beyond the areas in which Work is indicated. 2. Keep driveways and entrances serving the premises clear and available at all times to the Government, Governmen…