BATTERY ASSEMBLY

CONTACT INFORMATION|4|N711.13|GSK|771-229-0408|rachael.l.costanzo.civ@us.navy.mil| ITEM UNIQUE IDENTIFICATION AND VALUATION (JAN 2023)|19|||||||||||||||||||| INSPECTION OF SUPPLIES--FIXED-PRICE (AUG 1996)|2||| WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)|16|COMBO|N/A|TO BE DETERMINED (TBD)|N00104|TBD|TBD|W25G1U & W62G2T|TBD|||TBD|||||| NAVY USE OF ABILITYONE SUPPORT CONTRACTOR - RELEASE OF OFFEROR INFORMATION (3-18))|1|WSS| MANDATORY USE OF WORKFLOW PRO (WFP) MOD ASSIST MODULE|1|RACHAEL.L.COSTANZO.CIV@US.NAVY.MIL| BUY AMERICAN-FREE TRADE AGREEMENTS-BALANCE OF PAYMENTS PROGRAM-BASIC (FEB 2024)|11|||||||||||| NOTICE OF CYBERSECURITY MATURITY MODEL CERTIFICATION LEVEL REQUIREMENTS (NOV 2025))|1|| CONTRACTOR PURCHASING SYSTEM ADMINISTRATION-BASIC (DEVIATION 2026-O0015)|1|| SECURITY PROHIBITIONS AND EXCLUSIONS (CLASS DEVIATION 2026-O0025)(FEB 2026)|7|||||||| BUY AMERICAN-FREE TRADE AGREEMENTS-BALANCE OF PAYMENTS PROGRAM CERTIFICATE-BASIC (FEB 2024))|5|||||| BUY AMERICAN-BALANCE OF PAYMENTS PROGRAM CERTIFICATE-BASIC (FEB 2024)|1|| ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (DEVIATION 2026-O0043)(FEB 2026))|13|||||||||||||| NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PERPARDENESS, AND ENRGY PROGAM USE (APRIL 2008))|2||| This solicitation is issued pursuant to Emergency Acquisition Flexiblities (EAF). Accelerated delivery is encouraged and accepted before the delivery date(s) listed in the schedule. ^^ A. Electronic submission of any quotes, representations, and any necessary certifications shall be accomplished via an email directed to RACHAEL.L.COSTANZO.CIV@US.NAVY.MIL. B. General Requirements: MIL-STD Packaging, Government Source Inspection, FOB Source, CAV Reporting. C. This RFQ is for REPAIR. The resultant award of this solicitation will be issued bilaterally, requiring the contractor's written acceptance prior to execution. Verify nomenclature, part number, and NSN prior to responding. D. Only a firm-fixed (FFP), not-to-exceed (NTE) or estimated (EST) price for the REPAIR of the subject item(s) will be accepted. Quotes limited to test and evaluation (T&E) will NOT be accepted. The quoted price MUST be for the REPAIR of the item(s). E. Must adhere to IUID requirements of DFARS 252.211-7003 F. The ultimate awardee of the proposed contract action must be an authorized repair source. Award of the proposed contract action will not be delayed while an unauthorized source seeks to obtain authorization. G. The Government is requesting a Repair Turnaround Time (RTAT) of: 147 days after receipt of asset. Repair Turnaround Time (RTAT) definition: The resultant contractual delivery requirement is measured from asset Return to the date of asset acceptance under the terms of the contract. For purposes of this section, Return is defined as physical receipt of the F-condition asset at the contractor's facility as reflected in the Action Date entry in the Commercial Asset Visibility (CAV) system. In accordance with the CAV Statement of Work, the contractor is required to accurately report all transactions by the end of the fifth regular business day after receipt and the Action Date entered in CAV must be dated to reflect the actual date of physical receipt. The Contractor must obtain final inspection and acceptance by the Government for all assets within the RTATs established in this contract. Please note freight is handled by Navy CAV or Proxy CAV as stated in NAVSUPWSSFA24 or NAVSUPWSSFA25. Throughput Constraint: Contractor must provide a throughput Constraint for each NSN(s). Total assets to be repaired monthly after initial delivery commences: _____/month (contractor is to fill in #). A throughput of "0" (zero) per month reflects no throughput constraint. Induction Expiration Date: 180 days after contract award date. Any asset received after this date in days is not authorized for repair without bi-lateral agreement between the Contractor and NAVSUP WSS Contracting Officer. H. IMPORTANT NOTE: Reconciliation Price Reduction: Any asset(s) for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late. However, any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If the contractor does not meet the required RTAT due to inexcusable contractor delay, the Contracting Officer will implement the aforementioned price reduction via a "Reconciliation Modification" at the end of the contract performance. Price reductions made pursuant to this section shall not limit other remedies available to the Government for failure to meet required RTATs, including but not limited to the Government's right to terminate for default. In reference to the above important note, the contractor provides the following price reduction amount per unit/per month the contractor does not meet the RTAT: $___________, up to a maximum of: $__________. (vendor is to fill in amount) I. Your quote MUST include the following information for justification purposes: - Repair unit price ________________ - Total price________________ - Repair Turnaround Time (RTAT) _____________ days - New unit price ______________ NOTE: If you are not quoting the Government's Requested Repair Turnaround Time (RTAT) or sooner, you must provide your company's capacity constraints below: ___________________________________________________________________________ ___________________________________________________________________________ ___________________________________________________________________________ - T&E fee/price (if asset is determined BR/BER): If an item is determined BR, and the contractor provides documentation that costs were incurred during evaluation and determination of BR/BER, the contracting officer will negotiate a reduced contract price, not-to exceed (NTE) $___________associated with the repair effort to reflect the BR status of the equipment. - The T&E fee (if asset is determined BR/BER) was deter…