CANCELLATION NOTICE __ NDARNG- Onsite Medical Equipment Inspection/Calibration

1 Ver. October 2022 PERFORMANCE WORK STATEMENT (PWS) FOR Medical Equipment Inspection and Calibration Services North Dakota Army National Guard (NDARNG) 1.0 General: 1.1 Scope: The contractor shall provide all personnel, equipment, tools, materials, supervision, and quality control necessary, except as specified in Paragraph 3.0 as Government Furnished, to perform inspection and maintenance Services, as defined in this PWS. 1.2 Background: MTOE and TDA medical equipment inspection and calibration at Grand Forks, Fargo, Devils Lake, Minot and Bismarck ND. 1.3 Period of Performance (PoP): The Period of Performance shall be 1 Base Year of 12 months and two 12-month option years. 1.4 General Information: 1.4.1 Place and Performance of Services: The contractor shall provide services between the hours of 0800 - 1600 on Monday thru Friday, except on recognized US holidays or when the Government facility/installation is closed due to local or national emergencies, administrative closings, or similar Government-directed facility/installation closings. Performance shall be at each respective armory location.The contractor shall at all times maintain an adequate work force for the uninterrupted performance of all tasks defined within this PWS when the Government facility/installation is not closed for the above reasons. When hiring personnel, the contractor shall keep in mind that the stability and continuity of the work force are essential. Teleworking is not authorized 1.4.1.2 Unscheduled gate closures by the Security Police may occur at any time causing all personnel entering or exiting a closed installation to experience a delay. This cannot be predicted or prevented. Contractors are not compensated for unexpected closures or delays. Vehicles operated by contractor personnel are subject to search pursuant to applicable regulations. Any moving violation of any applicable motor vehicle regulation may result in the termination of the contractor employee’s installation driving privileges. 1.4.1.3 The contractor’s employees shall become familiar with and obey the regulations of the installation; including fire, traffic, safety and security regulations while on the installation. Contractor employees should only enter restricted areas when required to do so and only upon prior approval. All contractor employees shall carry proper identification with them at all times, and shall be subject to such checks as may be deemed necessary. The contractor shall ensure compliance with all regulations and -- 1 of 12 -- 2 Ver. October 2022 orders of the installation, which may affect performance. The Government reserves the right to direct the removal of an employee from Government property or revoke access to Government systems for misconduct, security reasons, or any overt evidence of communicable disease. Removal of contractor employees for reasons stated above does not relieve the Contractor from responsibility for total performance of this contract. 1.4.2 Recognized Holidays: The following are recognized United States (US) holidays. The contractor shall not perform services on these days: 1.4.2.1 New Year’s Day: January 1st 1.4.2.2 Martin Luther King, Jr.’s Birthday 1.4.2.3 President’s Day 1.4.2.4 Memorial Day 1.4.2.5 Juneteenth National Independence Day: June 19th 1.4.2.6 Independence Day: July 4th 1.4.2.7 Labor Day 1.4.2.8 Columbus Day 1.4.2.9 Veteran’s Day: November 11th 1.4.2.10 Thanksgiving Day 1.4.2.11 Christmas Day: December 25th 1.4.3 Quality Control (QC): The contractor shall develop and maintain an effective QC Plan (QCP) to ensure services are performed in accordance with this PWS. The contractor shall develop and implement procedures to identify, prevent, and ensure non- recurrence of defective services. The contractor’s QCP is the means by which it assures itself that its work complies with the requirements of the contract. As a minimum, the contractor shall develop QC procedures that address the areas identified in Technical Exhibit 1, Performance Requirements Summary (PRS). 1.4.4 Quality Assurance (QA): Reserved 1.4.5 Installation Access and Security Requirements. The contractor shall comply with all applicable installation/facility access and local security policies and procedures, which may be obtained from the COR. The contractor and all associated subcontractor employees shall provide all information required for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services, or Security Office. The contractor shall ensure compliance with all personal identity verification requirements as directed by Department of Defense (DoD), Headquarters Department of Army (HQDA) and/or local policy (see PWS 6.0). Should the Force Protection Condition (FPCON) change, the Government may require changes in contractor security matters or processes. -- 2 of 12 -- 3 Ver. October 2022 1.4.5.2 For contractors that do not require a CAC, but require access to a DoD facility or installation: Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05), and applicable installation, facility and area commander installation/facility access, and local security policies and procedures (provided by a Government representative). 1.4.5.3 Awareness Training (AT) Level 1: All contractor employees, including subcontractor employees, requiring access to Army installations, facilities, and controlled access areas shall complete AT Level 1 training within 30 calendar days after contract start date and within 30 calendar days of new employees commencing performance. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee to the COR. 1.4.5.4 Reserved. 1.4.5.5 Communications Security/Informatio…